Forwarding Provincial Housing Construction Office, "Guangdong Provincial Housing and Urban Construction Department of Construction Construction Period of the management approach"Management of Construction Period of Guangdong Provincial Housing and Urban - Rural Construction Department Method Article 1 These Measures are formulated in accordance with the relevant laws and regulations such as the Construction Law of the People's Republic of China, the Regulations on the Administration of Construction Engineering Quality, the Regulations on the Administration of Work Safety in Construction Projects, etc. in order to strengthen the management of the construction period of the construction project, ensure the reasonable construction period and ensure the construction quality and construction safety. Regulations and construction of mandatory standards, combined with the actual province, the development of this approach. Article 2 These Measures shall apply to the management of the construction period of new construction, alteration and extension construction projects in the administrative areas of our province. The term "construction project" as mentioned in the present Measures refers to the housing construction, municipal infrastructure and ancillary pipelines, equipment installation and decoration works. Article 3 The Provincial Department of Housing and Urban-Rural Development shall be responsible for the management of the construction period of construction projects throughout the province. The municipal, county (district) housing and urban and rural construction administrative departments in charge of the administrative area of the construction period management. Article 4 The bid inviter shall clearly stipulate the construction period required in the bidding documents, and the construction project that shall be tender according to law shall also specify the construction period of the construction standard. Construction period of the standard construction period, "Guangdong Province, the construction period of construction standards fixed" calculation to determine. If the project construction period can not be calculated due to the special construction, the actual construction period of the similar project may be referred to. The similar engineering reference should be reasonably determined according to the engineering scale, structure and construction difficulty. Article 5 If the tendering period is shorter than the construction standard construction period, the project shall be listed separately in the bidding quantity list and separately calculated in the bidding control price. The cost of the rush-up measures shall be calculated in accordance with the relevant provisions of "Guangdong Construction Engineering Valuation Basis" Specified calculation. Article 6 The duration of the bid shall be in accordance with the relevant time limit for the tender documents. If the bid construction plan adopts the measures for quickening the work, the bidder shall take the cost of the rush-up measures and rush the measures and shall not be taken as a profit-taking factor. Article VII of the tender evaluation committee should review the duration of the tender and related matters; bid period is shorter than the standard duration, but also the assessment of rush measures and rush measures measures. After evaluation, one of the following circumstances may not recommend the successful bidder: (1) the bid period does not meet the requirements of the tender documents; (B) the tender documents required to provide construction schedule, the bidder did not mention the progress of the construction plan or the construction schedule provided by the demonstration is considered not feasible; (3) The measure of rush-up measures and the measure of rush-up can not correspond and the bidder can not reasonably explain. Article 8 Both parties to the contract shall specify the duration of the contract and the responsibilities of the contractor both in terms of the duration of the construction contract, including: (1) to specify the number of calendar days for which the construction period of the contract is to be made, and the date of commencement and planned completion of the project; (2) Clearly delaying the completion of the responsibility, delaying the completion of the compensation standards and the maximum amount of compensation; (C) the duration of claims, duration and duration of the dispute settlement. The duration of the contract shall be determined in accordance with the bidding documents and the bid documents of the winning bidder. The duration of the tendering shall be decided by the contractor and the bidder shall be determined according to the standard duration of the contract. . If the construction contract does not specify the duration of the contract, it shall be determined by the contracting parties in accordance with the present Measures and the "Guangdong Provincial Construction Project Construction Period Quota" in consultation and a supplemental agreement shall be signed. Article 9 Prior to the formal implementation of the construction project, the Employer shall post a notice in a prominent position on the construction site and timely release the relevant information on the progress of the construction. Article 10 The commencement conditions prescribed in laws and regulations shall be met in the construction of the project. If the project does not meet the conditions for starting work, it shall not be included in the construction period. Article 11 The Contractor shall organize the construction in accordance with the construction schedule and ensure that the construction project is completed on time. If the contractor can not organize the construction according to the plan, it shall promptly take measures to adjust the construction schedule and submit it to the issuer for approval. Article 12 The Employer shall not arbitrarily compress the time limit stipulated in the contract. The Contractor shall have the right to lodge a complaint with the competent administrative department of construction, and the competent administrative department of construction at all levels shall organize the verification. If any illegal act is found, the Contractor shall, in accordance with the Regulations on Construction Engineering Quality Management and the Construction Safety Production Management Regulations, And other laws and regulations shall be ordered to correct, be punished. Article 13 During the construction of a construction project, the Employer and the Contractor shall adjust the construction period according to the stipulations and actual conditions of the construction contract, including: (1) to extend the duration. If the construction period is delayed due to the reasons of the non - contractor, the contractor shall confirm the construction period and extend the construction period. (B) increase the duration. If the contractor increases the content of the project, the contractor shall, in consultation with the contractor, decide to increase the construction period. Article 14 In the course of construction, the Employer may, as a result of objective reasons and design changes, delay the construction period and can not meet the requirements for use, the Employer may request the Contractor to shorten the construction period according to the circumstances of the unfinished Project. The Contractor shall have the right to refuse the Employer 's request, and may, as the case may be, propose a construction plan and expense report for shortening the construction period. In the project supervision unit to demonstrate the feasibility of shortening the duration of the construction program under the premise of the contract can be negotiated to shorten the construction period, and signed a supplementary agreement. Article 15 In the course of implementing the supervision, the project supervision unit shall, if it finds that the construction schedule of the contractor does not conform to the requirements of the contract, shall be ordered to be re-submitted after the modification; it shall be found that the contractor does not abide by the mandatory standards for project construction, , The contractor should be required to rectify the situation, in serious cases, the contractor should be required to temporarily stop the construction and timely reporting of the contract. Where the contractor refuses to make rectification or does not stop construction, the engineering supervision unit shall promptly report to the competent construction authority or the supervisory organ entrusted by the project location. Article 16 The actual date of completion of the contract works shall be determined in accordance with the following circumstances: (A) the completion of the construction contract quality inspection acceptance, in order to pass the completion of construction quality acceptance date for the actual completion date; (2) If the contractor submits the application report on the completion and acceptance of the construction quality, if the Employer fails to organize the completion and acceptance of the construction quality within the prescribed time, the contractor shall submit the construction quality completion and acceptance application report as the actual completion date; (3) If the contract works are not checked and accepted for construction quality completion and the Employer's unauthorized use is made, the date of transfer shall be the actual completion date. Article 17 During the construction of the project, the Employer, the Contractor and the Project Supervision Unit shall make a record and the contract period shall be adjusted in accordance with the contract when the time limit of the contract and the time limit for the construction contract are increased. In case of dispute, the contract shall be handled in accordance with the contract. Article 18 The competent administrative department of housing and urban and rural construction of the city and county (district) shall strengthen the supervision and management of the bid invitation market and the construction period of the construction site, strengthen the supervision over the tender documents, the construction contract and the construction operation; To stop violations of the construction period of irregular behavior, according to the law does not meet the quality of construction projects and production safety laws, regulations and mandatory standards for construction of illegal acts. Article XIX of the measures by the Guangdong Provincial Housing and Urban Construction Department is responsible for the interpretation. Article 20 These Measures shall enter into force as of November 1, 2012.
网站建设：亿天联科技